While this coronavirus event grips the nation, contractors and subcontractors are asking whether this qualifies as a force majeure or changed condition event. We think it qualifies as both.
When you bid and signed your contracts, if the force majeure clause was given any thought, it likely was about the impact of a hurricane hitting the job site. Would a hurricane shut a job down for three days, or four? Well, this coronavirus event is having an impact that will last three months, or more.
As lawyers, we can work safely from home. Construction, on the other hand, requires hands-on work. Laborers are concerned about their safety, but they have bills to pay and a family to feed. What should you do if a worker shows up sick and works for a day before their symptoms worsen and become obvious? Do you shut the whole job down, just that crew, or just send that laborer home? In your safety and other briefings, you should be emphasizing the importance of staying home as soon as you have any symptoms. Document that you said this in your daily reports.
We suggest that you read your contracts today. Look at the delay and other clauses like the changed conditions and claim clauses. In your contract, a force majeure event may get you more time, but not money. A changed condition clause might get both. If you are being impacted, get your Notices of Claim out, tailored to the exact requirements of each contract. Send it to everyone above you to whom notice must be given. In most contracts, you are required to use the word “Claim” in your notice, so do it if you are sending one.
Here is some suggested sample language:
“NOTICE OF CLAIM
We are giving notice of a Claim. The coronavirus is expected to impact our schedule and our costs. We are not at fault. We did not anticipate this event. We cannot control it. We do not know how long it will last. The situation is changing daily. President Trump has just granted Governor Abbott’s request to declare Texas a Disaster Area. At this time, we cannot predict how much additional time we will need, nor can we predict how much our costs will increase. We anticipate disruptions in our labor and in our materials supply lines. We will do what we can to mitigate these impacts, but with symptomatic workers being required to stay home, our onsite labor forces and our suppliers will all be impacted. We will update this Claim as we can. Thank you for your patience and understanding.”
Porter Hedges LLP
- A Cautionary Tale for Contractors: Releases in Contract Modifications and Preservation of Claims
- The Impact of New Texas Discovery Rules in Delay and Disruption Claims
- If You Seek to Limit the Authority of Your Arbitrators, Your Arbitration Clause Must Be Clear
- The Anatomy of a Change Order Clause in a Construction Contract
- Substantial Compliance – When the Contract Doesn’t Always Mean What it Says
- Ready to Settle with the General Contractor or its Bankruptcy Trustee, Subcontractors Should Proceed with Caution
- Recent Victory for All Texas Landowners Facing Pipeline Condemnation
- Navigating Austin Bridge – New Texas Supreme Court Case Upends Arbitration Framework Against Governmental Entities
- Is the Coronavirus Event a Force Majeure or Changed Condition Event?
- Small Business Economic Injury Disaster Loans